Loading...
24.11.25 SCA Baker Builders, LLC CA-1 CONSTRUCTION AGREEMENT THIS CONSTRUCTION AGREEMENT (“Agreement”) is entered into this 25 day of November, 2024 by and between: The Town of Avon, Colorado (hereinafter referred to as “OWNER”) and Baker Builders, LLC dba Baker Constructors (hereinafter referred to as “CONTRACTOR”). OWNER and CONTRACTOR, in consideration of the mutual covenants hereinafter set forth, agree as follows: Article 1. WORK 1.01 CONTRACTOR shall complete all Work as specified or indicated in the Contract Documents (defined below). The Work is generally described as follows: Civil, Landscape, Structural, Plumbing and Electrical improvements indicated in the Contract Documents including coordination, preparation and final utility (electric, domestic water, sanitary sewer) connections related a separate contract for procurement and installation of modular restrooms as indicated in the Contract Documents. Additional Work includes provision continuous insulation, exterior finish materials (stone), and associated flashings to the modular construction. Article 2. THE PROJECT 2.01 The project for which the Work under the Contract Documents may be the whole or only a part is generally described as follows: EAST NOTTINGHAM PARK IMPROVEMENTS (hereinafter referred to as the “Project”). Article 3. ENGINEER 3.01 The Town Engineer shall serve as construction management engineer (hereinafter referred to as “ENGINEER”) and who is to act as OWNER’S Representative, will assume all duties and responsibilities and will have the rights and authority assigned to ENGINEER and OWNER in the Contract Documents in connection with completion of the Work in accordance with the Contract Documents. Article 4. CONTRACTOR’S REPRESENTATIVES 4.01 In order to induce OWNER to enter into this Agreement, CONTRACTOR makes the following representations: A. CONTRACTOR has familiarized himself with the nature and extent of the contract documents, Work, locality, and with all local conditions and federal, state, and local laws, ordinances, rules and regulations that in any manner may affect the cost, progress, or performance of the Work. CA-2 B. CONTRACTOR has carefully studied all reports of investigations and tests of subsurface and latent physical conditions at the site or otherwise affecting the cost, progress, or performance of the Work which were relied upon by ENGINEER in the preparation of the Contract Documents, and which have been identified in the Special Conditions. C. CONTRACTOR has made or caused to be made examinations, investigations, tests, and studies of such reports and related data in addition to those referred to in paragraph 4.01(B) above, as he deems necessary for the performance of the Work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents; and no additional examinations, investigations, tests, reports, or similar data are or will be required by CONTRACTOR for such purposes. D. CONTRACTOR has correlated the results of all such observations, examinations, investigations, tests, reports and data with the terms and conditions of the Contract Documents. E. CONTRACTOR has given ENGINEER any conflicts, errors or discrepancies that he has discovered in the Contract Documents, and the written resolution thereof by ENGINEER is acceptable to CONTRACTOR. Article 5. CONTRACT TIME 5.01 TIME IS OF THE ESSENCE A. All time limits for Milestones, if any, Substantial Completion, and completion and readiness for final payment as stated in the Contract Documents are of the essence of the Contract. 5.02 DAYS TO ACHIEVE SUBSTANTIAL COMPLETION AND FINAL PAYMENT A. CONTRACTOR shall achieve Substantial Completion by May 8, 2026 provided the issuance by the OWNER of a Notice to Proceed is provided by April 1, 2025 and shall finally complete the Work so that it is ready for final payment by May 20, 2026. 5.03 LIQUIDATED DAMAGES A. Should the CONTRACTOR fail to complete the Work, or any part thereof, in the time stipulated in the Agreement or within such extra time as may have been allowed for delays by extensions granted as provided in the Contract Documents, the CONTRACTOR shall reimburse the OWNER for the additional expenses and damage for each calendar day, Sundays and holidays excluded, that the Contract remains uncompleted after the Contract completion date. It is agreed that the amount of such additional expense and damage, incurred by reason of failure to complete the Work, is $3,000.00 per day. The said amounts are hereby agreed upon as liquidated damages for the loss to the OWNER because of the impracticability and extreme difficulty of fixing and ascertaining the actual damages the OWNER would, in such event, sustain. B. It is expressly understood and agreed that this amount is not to be considered in the CA-3 nature of a penalty, but as liquidated damages which have accrued against the CONTRACTOR; and the OWNER is authorized to deduct the amount of such damages from any monies due the CONTRACTOR for Work performed or material furnished under this Agreement and the CONTRACTOR and his Sureties shall be liable for any excess C. In the event that this section conflicts with any other provision regarding liquidated damages within the Contract Documents, this section shall control. Article 6. CONTRACT PRICE 6.01 OWNER shall pay CONTRACTOR $3,940,836.00 (Three million nine hundred forty thousand eight hundred thirty six dollars) for completion of the Work as full compensation for everything furnished and done by CONTRACTOR under this Agreement, including all loss or damage arising out of the work; including increased prices for or shortages of materials for any reason; and for risks associated with the work to the extent it is under the CONTRACTOR’S control; for all expenses incurred due to the suspension or discontinuation of the work; and for well and faithfully completing the work as provided in this Agreement. Article 7. PAYMENT PROCEDURES 7.01 Submittal and Processing of Payments A. CONTRACTOR shall submit Applications for Payment to the OWNER on a monthly basis, which shall be processed by the ENGINEER. 7.02 Progress Payments; Retainage A. OWNER shall make progress payments towards the Contract Price, less five percent (5%) for retainage, on the basis of CONTRACTOR’S Applications for Payment, as verified and recommended by ENGINEER, on or about the twenty-fifth (25th) day of each month during performance of the Work. In the ENGINEER’S discretion, the OWNER may withhold some or all of a progress payment where the CONTRACTOR’S Application for Payment does not reflect the actual amount of the Work completed. 7.03 Final Payment A. Upon final completion and acceptance of the Work as recommended by the ENGINEER, OWNER shall pay the remainder of the Contract Price, including any retainage previously withheld. Article 8. PROJECT WARRANTIES 8.01 CONTRACTOR’S warranties in respect of the Work (the “Project Warranties”) are as follows: CONTRACTOR warrants to OWNER that the Work shall be fit for its intended purposes, that materials and equipment furnished under this Agreement shall be of good quality and new, that all Work shall be free from defects and that all Work shall meet all of CA-4 the requirements of this Agreement. CONTRACTOR shall furnish satisfactory evidence that it has met the Project Warranties. The Project Warranties shall commence on the date CONTRACTOR achieves final completion of the Work satisfactorily to OWNER. If at any time within two (2) years after the date on which the Project Warranties commenced, any portion of the Work is found to be not in accordance with the Project Warranties, CONTRACTOR shall correct it promptly after receipt of notice from OWNER to do so unless OWNER has previously given CONTRACTOR a written acceptance of such condition. Article 9. INSURANCE 9.01 Insurance Requirements A. CONTRACTOR shall not commence work under this Agreement until CONTRACTOR has obtained all insurance required under Article 5 of the General Conditions and the insurance has been approved by the Town Manager or his designee. The Town of Avon shall be named as an additional insured. Certificates of insurance shall be issued prior to execution of the Notice to Proceed. Additionally, CONTRACTOR shall not allow any approved subcontractor to commence work on his or her subcontract until all similar insurance required of subcontractor has been so obtained and approved. Article 10. CONTRACTOR’S REPRESENTATIONS 10.01 In order to induce OWNER to enter into this Agreement, CONTRACTOR makes the following representations: A. CONTRACTOR has examined, carefully studied, and familiarized himself with the nature and extent of the Contract Documents and the other related data identified in the Bidding Documents as well as work, locality, and all local conditions and federal, state, and local laws, ordinances, rules, and regulations that in any manner may affect the cost, progress, or performance of the works. B. CONTRACTOR has visited the Site and become familiar with and is satisfied as to the general, local, and Site conditions that may affect cost, progress, and performance of the work in addition to carefully studying all reports of investigations and tests of subsurface and latent physical conditions at the site, or otherwise, affecting the cost, progress, or performance of the Work which were relied upon by the ENGINEER in the preparation of the Contract Documents and which have been identified in the Special Conditions. C. CONTRACTOR has obtained and carefully studied (or assumes responsibility for having done so) any examinations, investigations, explorations, tests, studies, and data concerning conditions at or contiguous to the Site which may affect cost, progress, or performance of the Work or which relate to any aspect of the means, methods, techniques, sequences, and procedures of construction to be employed by CONTRACTOR, including applying the specific means, methods, techniques, sequences, and procedures of construction, if any, expressly required by the Contract Documents to be employed by CONTRACTOR, and safety precautions and programs CA-5 incident thereto. D. CONTRACTOR does not believe that any further examinations, investigations, explorations, tests, studies, or data are necessary or will be required by CONTRACTOR for the performance of the Work at the Contract Price, within the Contract Times, and in accordance with the other terms and conditions of the Contract Documents. E. CONTRACTOR is aware of the general nature of work to be performed by OWNER and others at the Site that relates to the Work as indicated in the Contract Documents. F. CONTRACTOR has correlated the information known to CONTRACTOR, information and observations obtained from visits to the Site, reports and drawings identified in the Contract Documents, and all additional examinations, investigations, explorations, tests, studies, and data with the Contract Documents. G. CONTRACTOR has given ENGINEER written notice of all conflicts, errors, ambiguities, or discrepancies that CONTRACTOR has discovered in the Contract Documents, and the written resolution thereof by ENGINEER is acceptable to CONTRACTOR. H. The Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. I. CONTRACTOR warrants and guarantees to OWNER and ENGINEER that all Work will be in accordance with the Contract Documents and will not be defective within two (2) years of Substantial Completion. J. CONTRACTOR is organized, validly existing and in good standing under the laws of the State of Colorado and has all requisite power to own its properties and assets and carry on its business as now conducted or proposed to be conducted. Article 11. CONTRACT DOCUMENTS 11.01 CONTENTS A. The Contract Documents which comprise the entire agreement between OWNER and CONTRACTOR are attached to this Agreement, are incorporated by reference as if fully set forth herein, and consist of the following: 1. Advertisement for Bid (pages AB-1 to AB-2) 2. Instruction to Bidders (pages IB-1 to IB-6) 3. Performance (pages PB-1 to PB-2) and other Bonds (pages LMB-1, LMB-2, Power of Attorney), identified as exhibits A & B and consisting of 5 pages. 4. Notice of Award (page NA-1) CA-6 5. Construction Agreement (pages CA-1 to CA-9) 6. Notice to Proceed (page NP-1) 7. General Conditions (pages GC-1 to GC-48 , inclusive) 8. Special Conditions (pages SC-1 to SC-16 , inclusive) 9. Plans, consisting of sheets listed below by number, title, date and revision number with each sheet, Specifications, and References: a. CONSTRUCTION DRAWINGS: EAST NOTTINGHAM PARK IMPROVEMENTS PROJECT in Avon, Colorado ISSUE B – SITE AND INFRASTRUCTURE BID SET, July 25, 2024, Zehren and Associates Inc, 53 Sheets inclusive. b. SPECIFICATIONS: EAST NOTTINGHAM PARK IMPROVEMENTS PROJECT; Project Specifications 20212859.05, Issue B–Bid Set, July 25, 2024, Zehren and Associates Inc. c. ATTACHMENT A: GEOTECHNICAL EVALUATION NOTTINGHAM PARK RESTROOMS AVON, CO; Prepared by Ground Engineering, January 19, 2022, Job #21-6005 10. Addenda numbers 1 to 4, inclusive 11. Contractor’s Bid (pages BF-6 to BF-10, inclusive) marked exhibit C. 12. Documentation submitted by CONTRACTOR prior to Notice of Award (pages 1 to 9, inclusive) marked exhibit D. B. Any written Amendments, Modifications, or Work Change Orders which may be delivered or issued on or after the Effective Date of the Agreement that are not attached hereto. There are no Contract Documents other than those listed above in this Article. C. The Contract Documents may only be altered, amended, modified, supplemented, or repealed by written agreement signed by both parties. Article 12. PERFORMANCE BOND 12.01 To secure performance of CONTRACTOR’S obligations under this Agreement, the CONTRACTOR shall provide the OWNER with a Performance Bond in the amount of the full contract price. Prior to execution of this Agreement, the CONTRACTOR shall provide the form of the Performance Bond to the Town for its review and approval. The Town shall be authorized to draw upon the Performance Bond to correct any default by Builder under this Agreement, which default shall be determined and substantiated by an Affidavit of Default signed by the ENGINEER. The Performance Bond shall be held by the Town through the two (2) year Project Warranties period specified in this Agreement. CA-7 Article 13. MISCELLANEOUS 13.01 Terms Used in this Agreement A. The terms used in this Agreement, which are defined in Article 1 of the General Conditions, shall have the meanings set forth therein. 13.02 Indemnification A. The CONTRACTOR agrees to indemnify, save, and hold harmless the OWNER, its officers, employees, and agents from any and all liability, loss, costs, charges, obligations, expenses, attorney’s fees, litigation, judgments, damages, claims, and demands of any kind arising from or out of any negligent act, error, omission or other tortious conduct of the CONTRACTOR, its officers, subcontractors, employees, or agents in the performance or non-performance of its obligations under this Agreement. 13.03 Assignment of Contract A. No assignment by a party hereto of any rights under, or interests in, the Contract will be binding on another party hereto without the written consent of the party sought to be bound; and, specifically but without limitation, moneys that may become due and moneys that are due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 13.04 Successors and Assigns A. OWNER and CONTRACTOR each binds itself, its partners, successors, assigns, and legal representatives to the other party hereto, its partners, successors, assigns, and legal representatives in respect to all covenants, agreements, and obligations contained in the Contract Documents. 13.05 Severability A. Any provision or part of the Contract Documents held to be void or unenforceable by any court of competent jurisdiction shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon OWNER and CONTRACTOR, who agree that the Contract Documents shall be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. 13.06 Independent Contractor A. The CONTRACTOR shall perform the Services as an independent contractor and shall not be deemed by virtue of this Agreement to have entered into any partnership, joint venture, employer/employee relationship with the OWNER other than as a contracting party and independent contractor/the OWNER shall not be obligated to secure, and shall not provide, any insurance coverage or employment benefits of any kind or type CA-8 to or for the CONTRACTOR or the CONTRACTOR’s employees, sub-consultants, contractors, agents, or representatives, including coverage benefits related but not limited to: local, state, or federal income or other tax contributions; insurance contributions (e.g., FICA); workers' compensation; disability, injury, or health; professional liability insurance, errors, and omissions insurance; or retirement account contributions. 13.07 No Waiver of Governmental Immunity A. Nothing herein is intended as nor shall it be construed as a waiver of the protections and immunities afforded the OWNER pursuant to the Colorado Governmental Immunity Act, Sections 24-10-101, et seq., Colorado Revised Statutes, or pursuant to any other applicable laws. 13.08 Governing Law, Venue, Enforcement A. This Agreement shall be governed by and interpreted according to the law of the state of Colorado. Venue for any action arising under this Agreement shall be in the appropriate Court in Eagle County, Colorado. The Parties hereby waive any and all right either may have to request a jury trial in any civil action relating primarily to the enforcement of this Agreement in order to reduce the cost of dispute resolution and to expedite the resolution of disputes under this Agreement. The parties agree that the rule providing ambiguities in a contract are to be construed against the drafting party shall not apply to the interpretation of this Agreement. If there is any conflict between the language of this Agreement and any exhibit or attachment, the language of this Agreement shall govern. 13.09 Other Provisions A. Pursuant to Section 24-91-103.6, C.R.S., the OWNER hereby states that it has appropriated an amount equal to or in excess of the Contract amount. OWNER shall not issue a Change Order, or other form of order or directive requiring additional compensable work to be performed, which work causes the aggregate amount payable under the Contract to exceed the amount appropriated for the original Contract unless CONTRACTOR is given written assurance by the public entity that lawful appropriations to cover the costs of the additional work have been made. B. Certain verbiage contained in the Construction Agreement and Special Conditions conflict with language in the General Conditions. It is noted that language in the Construction Agreement and Special Conditions does not negate conflicting language in the General Conditions. IN WITNESS WHEREOF, the parties hereto have signed this Agreement in triplicate. One counterpart each has been delivered to OWNER, CONTRACTOR, and ENGINEER. All portions of the Contract Documents have been signed or identified by OWNER and CONTRACTOR or by ENGINEER on their behalf. This Agreement will be effective on November 25, 2024. CA-9 OWNER, TOWN OF AVON By: ________________________________ Printed Name: Amy Phillips Title: Mayor APPROVED AS TO FORM By: Nina P. Williams, Town Attorney ADDRESS FOR GIVING NOTICES: Town of Avon Attn: Town Attorney PO Box 975 Avon, CO 81620 CONTRACTOR, By: _________________________________ Printed Name: Dustin Baker Title: President ADDRESS FOR GIVING NOTICES: Baker Constructors 5660 Iris Parkway Frederick, CO 80504 License No. 021394 AGENT FOR SERVICE OF PROCESS: Dustin Baker _______________________________ _______________________________ _______________________________ Dustin Baker (Nov 26, 2024 11:45 MST) Nina P. Williams (Nov 26, 2024 11:46 MST) ID Task Name Duration Start Finish Predecessors 1 Avon Nottingham Park Construction Schedule 190 days Tue 8/27/24 Mon 6/2/25 2 SELECTION 16 days Tue 8/27/24 Wed 9/18/24 3 Submit Proposal 1 day Tue 8/27/24 Tue 8/27/24 4 Selection 2 wks Wed 8/28/24 Wed 9/11/24 3 5 Notice of Award 1 day Thu 9/12/24 Thu 9/12/24 4 6 Negotiate/Execute Contract 1 wk Thu 9/12/24 Wed 9/18/24 4 7 Notice To Proceed 0 days Wed 9/18/24 Wed 9/18/24 6 8 PRECONSTRUCTION 21 days Thu 9/19/24 Thu 10/17/24 9 Kickoff Meeting with Town of Avon 1 day Thu 9/19/24 Thu 9/19/24 7 10 Precon Meeting with Holy Cross Energy 1 day Fri 9/20/24 Fri 9/20/24 9 11 Procure Holy Cross Primary Electrical Gear 2 wks Mon 9/23/24 Fri 10/4/24 10 12 Prepare SWMP Plan 2 wks Thu 9/19/24 Wed 10/2/24 7 13 Submit Colorado Stormwater Permit 10 days Thu 10/3/24 Wed 10/16/24 12 14 Obtain Stormwater Approval 1 day Thu 10/17/24 Thu 10/17/24 6,13 15 PROCUREMENT 189 days Wed 8/28/24 Mon 6/2/25 16 Prefab Modular Structures 189 days Wed 8/28/24 Mon 6/2/25 3 17 Holy Cross Electrical Gear 4 wks Mon 9/23/24 Fri 10/18/24 7,10 18 Canopy Structure 8 wks Thu 9/19/24 Wed 11/13/24 7 19 Utility Piping 4 wks Thu 9/19/24 Wed 10/16/24 7 20 Site Lighting 12 wks Thu 9/19/24 Fri 12/13/24 7 21 Panels and Gear 12 wks Thu 9/19/24 Fri 12/13/24 7 22 CONSTRUCTION 142 days?Mon 3/31/25 Thu 10/30/25 23 Phase 1 (Before 6/27)76 days?Mon 3/31/25 Tue 7/29/25 24 Primary Electrical Service 70.5 daysMon 3/31/25 Tue 7/22/25 25 Let Mud Season Pass 1 day Mon 3/31/25 Mon 3/31/25 26 Install Erosion Control 5 days Tue 4/1/25 Mon 4/7/25 14,25 27 Install Temp Fence 5 days Tue 4/1/25 Mon 4/7/25 26FF 28 Remove Trees at new Tranformer Location 1 day Tue 4/8/25 Tue 4/8/25 26 29 Install Transformer Vaults 2 days Wed 4/9/25 Thu 4/10/25 28 30 July 4rth Celebration 1 day Mon 6/23/25 Mon 7/7/25 31 Transformer to V3 - 283 LF 14.5 daysWed 4/9/25 Tue 4/29/25 32 Sawcut/Remove Asphalt for Trenching 1 day Wed 4/9/25 Wed 4/9/25 28 33 Stockpile Gravel 1 day Thu 4/10/25 Thu 4/10/25 32 Mar Apr May Jun Jul Aug Sep Oct Qtr 2, 2025 Qtr 3, 2025 Qtr 4, 2025 Task Split Milestone Summary Project Summary Inactive Task Inactive Milestone Inactive Summary Manual Task Duration-only Manual Summary Rollup Manual Summary Start-only Finish-only External Tasks External Milestone Deadline Progress Manual Progress Nottingham Park Improvements Page 1 Project: Preconst Schedule Date: Tue 8/27/24 ID Task Name Duration Start Finish Predecessors 34 Pothole 24" Water Line crosssing 1 day Thu 4/10/25 Thu 4/10/25 32 35 Trenching 3 days Fri 4/11/25 Tue 4/15/25 34 36 Lay Conduit (2 ea 4" + Light Pole conduits) 3 days Wed 4/16/25 Fri 4/18/25 35 37 Excavate Set and backfill V3 1 day Mon 4/21/25 Mon 4/21/25 36 38 Inspect (Holy Cross & State)1 day Tue 4/22/25 Tue 4/22/25 37 39 Backfill trenching 3 days Wed 4/23/25 Mon 4/28/25 38,119 40 Replace Asphalt Section 1 day Mon 4/28/25 Tue 4/29/25 39 41 Replace Gravel Base 1 day Mon 4/28/25 Tue 4/29/25 39 42 V3 to V4 12 days Wed 4/23/25 Mon 5/12/25 43 Install Waddle Protection 1 day Wed 4/23/25 Thu 4/24/25 39SS 44 Remove Fences 1 day Thu 4/24/25 Fri 4/25/25 43 45 Strip Topsoil 1 day Fri 4/25/25 Mon 4/28/25 44 46 Pothole Steel Casing 1 day Fri 4/25/25 Mon 4/28/25 44 47 Pothole 24" Water Line crosssing 1 day Fri 4/25/25 Mon 4/28/25 46FF 48 Pothole Phone Line 1 day Fri 4/25/25 Mon 4/28/25 46FF 49 Trenching - 164 LF 2 days Mon 4/28/25 Wed 4/30/25 48,44 50 Lay Conduit (2 ea 4")2 days Wed 4/30/25 Fri 5/2/25 49 51 Excavate Set and backfill V4 1 day Fri 5/2/25 Tue 5/6/25 50 52 Inspect 1 day Tue 5/6/25 Wed 5/7/25 51 53 Backfill trenching 2 days Wed 5/7/25 Fri 5/9/25 52 54 Replace Topsoil & Seed 1 day Fri 5/9/25 Mon 5/12/25 53 55 V4 to 263 & 263A Transformers 35 days Tue 5/20/25 Tue 7/22/25 56 Trench/Bore past HP Building 1 wk Tue 5/20/25 Tue 5/27/25 87 57 Install Conduit past HP Building 1 day Tue 5/27/25 Wed 5/28/25 56 58 Inspect conduit 1 day Wed 5/28/25 Thu 5/29/25 57 59 Backfill 3 days Thu 5/29/25 Tue 6/3/25 58 60 Inspect/repair damage to HP Building 1 wk Tue 6/3/25 Tue 6/10/25 59 61 Strip Grass & Topsoil/Stockpile 1 day Tue 6/3/25 Wed 6/4/25 59 62 Trench to Road Crossing - 444 LF 5 days Wed 6/4/25 Wed 6/11/25 61 63 Excavate, set & Backfill Unplanned Vault1 day Wed 6/11/25 Thu 6/12/25 62 64 Inspection 1 day Thu 6/12/25 Fri 6/13/25 63 65 Backfill 5 days Fri 6/13/25 Fri 6/20/25 64 66 Install Temp Road 2 days Fri 6/20/25 Tue 7/8/25 65 67 Set Up Traffic Control 0.5 days Tue 7/8/25 Tue 7/8/25 66 68 Sawcut and Remove Asphalt 0.5 days Wed 7/9/25 Wed 7/9/25 67 Mar Apr May Jun Jul Aug Sep Oct Qtr 2, 2025 Qtr 3, 2025 Qtr 4, 2025 Task Split Milestone Summary Project Summary Inactive Task Inactive Milestone Inactive Summary Manual Task Duration-only Manual Summary Rollup Manual Summary Start-only Finish-only External Tasks External Milestone Deadline Progress Manual Progress Nottingham Park Improvements Page 2 Project: Preconst Schedule Date: Tue 8/27/24 ID Task Name Duration Start Finish Predecessors 69 Locates and Potholing 3 days Wed 7/9/25 Mon 7/14/25 68 70 Trench across Road to Transformers 2 days Wed 7/9/25 Fri 7/11/25 68 71 Install Conduits 1 day Fri 7/11/25 Mon 7/14/25 70 72 Inspect 1 day Mon 7/14/25 Tue 7/15/25 71 73 Backfill 1 day Tue 7/15/25 Wed 7/16/25 72 74 Repave 1 day Wed 7/16/25 Thu 7/17/25 73 75 Remove Barricades 0.5 days Thu 7/17/25 Thu 7/17/25 74 76 Remove Temp Road 0.5 days Fri 7/18/25 Fri 7/18/25 75 77 Replace Topsoil 1 day Fri 7/18/25 Mon 7/21/25 76 78 Reseed 1 day Mon 7/21/25 Tue 7/22/25 77 79 Transformer to EX2 7 days Fri 5/9/25 Tue 5/20/25 80 Survey Parking Lot Elevations 0.5 days Fri 5/9/25 Fri 5/9/25 53,225 81 Coordinate Conduit Elevations 0.5 days Mon 5/12/25 Mon 5/12/25 80 82 Trench to EX2 2 days Mon 5/12/25 Wed 5/14/25 81 83 Install 2 new 4" Conduits - 144 LF 1 day Wed 5/14/25 Thu 5/15/25 82 84 Connect to existing Vault 0.5 days Thu 5/15/25 Thu 5/15/25 83 85 Adjust Manhole Elevation 1 day Fri 5/16/25 Fri 5/16/25 84 86 Inspect 0.5 days Mon 5/19/25 Mon 5/19/25 85 87 Backfill 1 day Mon 5/19/25 Tue 5/20/25 86 88 EX2 to V1 29.5 daysMon 5/19/25 Fri 7/11/25 89 Re-coordinate Conduit Elevations 0.5 days Mon 5/19/25 Mon 5/19/25 86 90 Sawcut and remove asphalt in lower parking lot 3 days Tue 5/20/25 Thu 5/22/25 89 91 Barricades and signage at Lake Street 1 day Fri 5/23/25 Fri 5/23/25 90 92 Remove Sidewalk Section 2 days Mon 5/26/25 Tue 5/27/25 84,91 93 Sawcut Asphalt 1 day Wed 5/28/25 Wed 5/28/25 92 94 Remove C&G 1 day Thu 5/29/25 Thu 5/29/25 93 95 Remove Asphalt at Lake Street 2 days Fri 5/30/25 Mon 6/2/25 94 96 Trench to V2 - 287 LF 1 wk Tue 6/3/25 Mon 6/9/25 95 97 Install conduit to V2 2 days Tue 6/10/25 Wed 6/11/25 96 98 Inspect 1 day Thu 6/12/25 Thu 6/12/25 97 99 Backfill between EX2 & V2 2 days Fri 6/13/25 Mon 6/16/25 98 100 Excavate between vaults in Lake Street 1 day Tue 6/17/25 Tue 6/17/25 99 101 Conduits and vaults in Lake Street 1 day Tue 6/17/25 Tue 6/17/25 99 102 Final Primary Inspection 1 day Wed 6/18/25 Wed 6/18/25 101 103 Backfill and Regrade Lake Street 2 days Thu 6/19/25 Fri 6/20/25 101,102 Mar Apr May Jun Jul Aug Sep Oct Qtr 2, 2025 Qtr 3, 2025 Qtr 4, 2025 Task Split Milestone Summary Project Summary Inactive Task Inactive Milestone Inactive Summary Manual Task Duration-only Manual Summary Rollup Manual Summary Start-only Finish-only External Tasks External Milestone Deadline Progress Manual Progress Nottingham Park Improvements Page 3 Project: Preconst Schedule Date: Tue 8/27/24 ID Task Name Duration Start Finish Predecessors 104 Repave Lake Street 2 days Mon 7/7/25 Tue 7/8/25 103 105 Pour Back Sidewalk 1 day Wed 7/9/25 Wed 7/9/25 104 106 Striping and Signage 1 day Thu 7/10/25 Thu 7/10/25 105 107 Remove Barricades 1 day Fri 7/11/25 Fri 7/11/25 106 108 Power Relocation and Turnover 7 days Wed 6/18/25 Thu 7/10/25 109 Final Holy Cross Inspection 1 day Wed 6/18/25 Wed 6/18/25 102FF 110 Pull Primary Power Feeds 5 days Thu 6/19/25 Wed 7/9/25 109 111 De-Energize Transformers 1 day Thu 7/10/25 Thu 7/10/25 110 112 Relocate Transformers 1 day Thu 7/10/25 Thu 7/10/25 111FF 113 Re-Energize Transformers 1 day Thu 7/10/25 Thu 7/10/25 112FF 114 Secondary Power 41 days?Fri 4/11/25 Mon 6/9/25 115 Install Secondary beteen Transformer & V37.5 days?Wed 4/16/25 Fri 4/25/25 116 Demo Concrete Pad 1 day Wed 4/16/25 Wed 4/16/25 35 117 Drill and set Light Pole Cages 2 days Thu 4/17/25 Fri 4/18/25 116 118 Install PES Conduit to Parks Light Pole 0.5 wks Mon 4/21/25 Wed 4/23/25 117,36 119 Install PES Conduit to Cabin Light Pole 0.5 wks Mon 4/21/25 Wed 4/23/25 36,117 120 Inspect 1 day?Wed 4/23/25 Thu 4/24/25 118,119 121 Pour Light Pole Bases 1 day?Thu 4/24/25 Fri 4/25/25 120 122 South Parking Lot Secondary (Light Poles & EV Stub) 10 days? Fri 5/9/25 Thu 5/22/25 123 Survey TBC & Pole locations 1 day Fri 5/9/25 Fri 5/9/25 80FF 124 Drill and install Lightpole Cages (2)1 day Mon 5/12/25 Mon 5/12/25 123 125 Trench to Light Pole Location 1 day Wed 5/14/25 Thu 5/15/25 124,82 126 Trench for South EV chargers 1 day Thu 5/15/25 Fri 5/16/25 125 127 Install Conduit to 1st pole 0.5 days Fri 5/16/25 Fri 5/16/25 126 128 Install conduit to 2nd light pole 0.5 days Mon 5/19/25 Mon 5/19/25 127 129 Install conduit to behind curb for EV Circuit0.5 days Mon 5/19/25 Mon 5/19/25 128 130 State Electrical Inspection 1 day Tue 5/20/25 Tue 5/20/25 129 131 Pour Light Pole Bases (2)1 day?Wed 5/21/25 Wed 5/21/25 130 132 Backfill 1 day?Thu 5/22/25 Thu 5/22/25 131,87FF 133 New Feeder for Stage (2nd Crew)26 days Fri 4/11/25 Mon 5/19/25 134 Demo Balance of Sidewalk 1 day Fri 4/11/25 Fri 4/11/25 29 135 Survey Light Pole & Sidewalk Locations 1 day Mon 4/14/25 Mon 4/14/25 134 136 Trench to Existing Pull Box - 306 LF 6 days Tue 4/15/25 Tue 4/22/25 135 137 Drill and set Light Pole Cages 1 day Wed 4/23/25 Wed 4/23/25 136 138 Trench Stub Out for West Seatwall 0.5 days Thu 4/24/25 Thu 4/24/25 137 Mar Apr May Jun Jul Aug Sep Oct Qtr 2, 2025 Qtr 3, 2025 Qtr 4, 2025 Task Split Milestone Summary Project Summary Inactive Task Inactive Milestone Inactive Summary Manual Task Duration-only Manual Summary Rollup Manual Summary Start-only Finish-only External Tasks External Milestone Deadline Progress Manual Progress Nottingham Park Improvements Page 4 Project: Preconst Schedule Date: Tue 8/27/24 ID Task Name Duration Start Finish Predecessors 139 Trench for North Parking Lights 1 day Thu 4/24/25 Fri 4/25/25 138 140 Trench Stub Out for Modular Connection0.5 days Fri 4/25/25 Fri 4/25/25 139 141 Install Conduit (2 ea 4", 6 ea 1"), 8 days Mon 4/28/25 Thu 5/8/25 140 142 State Electrical Inspection 1 day Fri 5/9/25 Fri 5/9/25 141 143 Backfill 6 days Mon 5/12/25 Mon 5/19/25 142 144 To Future Skate Park/East seat Wall 10.5 daysTue 5/20/25 Tue 6/3/25 145 Survey elevations of Paver Pad 1 day Tue 5/20/25 Tue 5/20/25 143 146 Coordinate Conduit Elevations Locations0.5 days Wed 5/21/25 Wed 5/21/25 145 147 Trench to East Seat Wall Stub Out - 221 LF1 wk Wed 5/21/25 Wed 5/28/25 146 148 Stub out for Future SW skate Park Light1 day Wed 5/28/25 Thu 5/29/25 147 149 Stub behind C&G for EV Chargers 1 day Thu 5/29/25 Fri 5/30/25 148 150 State Electrical Inspection 1 day Fri 5/30/25 Mon 6/2/25 149 151 Backfill & Mark Stub Out Locations 1 day Mon 6/2/25 Tue 6/3/25 150 152 Fiber Optics Conduit 20 days?Tue 5/13/25 Mon 6/9/25 153 Install Sleeve under Foundation 1 day Tue 5/13/25 Tue 5/13/25 206FF 154 Coordinate Depth with Secondary 1 day Fri 5/23/25 Fri 5/23/25 208 155 Trench - 150 LF 1 day Mon 5/26/25 Mon 5/26/25 154 156 TOA Inspection?1 day Tue 5/27/25 Tue 5/27/25 155 157 Backfill and Mark End of Conduit 1 day Wed 5/28/25 Wed 5/28/25 156 158 Make Final connection 1 day?Mon 6/9/25 Mon 6/9/25 220 159 Wet Utilities 70 days?Tue 4/8/25 Tue 7/29/25 160 Sanitary 12 days Tue 5/13/25 Wed 5/28/25 161 Install Sleeve under Footer 1 day Tue 5/13/25 Tue 5/13/25 206FF 162 Sawcut & Remove Asphalt for Sanitary 3 days Wed 5/14/25 Fri 5/16/25 161 163 Demo/Remove Sidewalk adjacent to Modulars 1 day Mon 5/19/25 Mon 5/19/25 162 164 Trench 2 days Tue 5/20/25 Wed 5/21/25 163 165 Install SS & Cleanout & Cap 2 days Thu 5/22/25 Fri 5/23/25 164 166 Inspection 1 day Mon 5/26/25 Mon 5/26/25 165 167 Backfill & Temp Patch 2 days Tue 5/27/25 Wed 5/28/25 166 168 Water Line 23 days?Tue 5/13/25 Thu 6/12/25 169 Install sleeve Under Footer 1 day Tue 5/13/25 Tue 5/13/25 206FF 170 sawcut & Remove Asphalt 2 days Fri 5/23/25 Mon 5/26/25 208 171 Trench for Water Line to Modulars 3 days Tue 5/27/25 Thu 5/29/25 170 172 Run 4" DIP to Modulars 2 days Fri 5/30/25 Mon 6/2/25 171 173 Pour Thrust blocks 1 day?Tue 6/3/25 Tue 6/3/25 172 Mar Apr May Jun Jul Aug Sep Oct Qtr 2, 2025 Qtr 3, 2025 Qtr 4, 2025 Task Split Milestone Summary Project Summary Inactive Task Inactive Milestone Inactive Summary Manual Task Duration-only Manual Summary Rollup Manual Summary Start-only Finish-only External Tasks External Milestone Deadline Progress Manual Progress Nottingham Park Improvements Page 5 Project: Preconst Schedule Date: Tue 8/27/24 ID Task Name Duration Start Finish Predecessors 174 Pressure Test 1 day Wed 6/4/25 Wed 6/4/25 173 175 Chlorinte and Flush 1 wk Thu 6/5/25 Wed 6/11/25 174 176 Backfill and Temp Patch 1 day Thu 6/12/25 Thu 6/12/25 175 177 Extend Fire Line 53 days Tue 4/8/25 Fri 6/20/25 178 Remove Flagpoles 1 day Tue 4/8/25 Tue 4/8/25 27 179 Excavate, expose Fire Hydrant 1 day Tue 6/3/25 Tue 6/3/25 172 180 Survey new Location 1 day Wed 6/4/25 Wed 6/4/25 179 181 Extend Fire Hydrant 2 days Thu 6/5/25 Fri 6/6/25 180 182 Pour Thrust Block 3 days Mon 6/9/25 Wed 6/11/25 181 183 Pressure Test 1 day Thu 6/12/25 Thu 6/12/25 182 184 Chlorinate & Flush 1 wk Fri 6/13/25 Thu 6/19/25 183 185 Backfill 1 day Fri 6/20/25 Fri 6/20/25 184 186 Roof Drain 9 days?Mon 7/7/25 Thu 7/17/25 187 Survey Roof Drain /Area Drain locations 1 day?Mon 7/7/25 Mon 7/7/25 224 188 Install 6" line to Rain Garden 3 days Tue 7/8/25 Thu 7/10/25 187 189 Coordinate Downspout Locations 1 day Fri 7/11/25 Fri 7/11/25 188 190 Trenching 2 days Mon 7/14/25 Tue 7/15/25 189 191 Install 4" SDR 35 to Wye 1 day Wed 7/16/25 Wed 7/16/25 190 192 Backfill 1 day Thu 7/17/25 Thu 7/17/25 191 193 Storm Drain 8 days Fri 7/18/25 Tue 7/29/25 194 Survey Grate Locations 1 day Fri 7/18/25 Fri 7/18/25 192 195 Trenching 1 day Mon 7/21/25 Mon 7/21/25 194 196 Install SDR 1 day Tue 7/22/25 Tue 7/22/25 195 197 Set Concrete Inlet 1 day Wed 7/23/25 Wed 7/23/25 196 198 Trenching 1 day Thu 7/24/25 Thu 7/24/25 197 199 Install SDR 1 day Fri 7/25/25 Fri 7/25/25 198 200 Backfill 2 days Mon 7/28/25 Tue 7/29/25 199 201 Modular Foundation 64 days Tue 4/1/25 Mon 7/14/25 202 Survey 1 day Tue 4/1/25 Tue 4/1/25 25 203 Excavate/Soil Prep 1 wk Wed 4/2/25 Tue 4/8/25 202 204 Resurvey 1 day Wed 4/9/25 Wed 4/9/25 203 205 Install Micropiles 20 days Thu 4/10/25 Thu 5/8/25 204 206 Form/Pour Spread Footers 3 days Fri 5/9/25 Tue 5/13/25 205 207 Form Pour Walls 1 wk Wed 5/14/25 Tue 5/20/25 206 208 Backfill To top of Crawl Space 2 days Wed 5/21/25 Thu 5/22/25 207 Mar Apr May Jun Jul Aug Sep Oct Qtr 2, 2025 Qtr 3, 2025 Qtr 4, 2025 Task Split Milestone Summary Project Summary Inactive Task Inactive Milestone Inactive Summary Manual Task Duration-only Manual Summary Rollup Manual Summary Start-only Finish-only External Tasks External Milestone Deadline Progress Manual Progress Nottingham Park Improvements Page 6 Project: Preconst Schedule Date: Tue 8/27/24 ID Task Name Duration Start Finish Predecessors 209 Form/Pour Leav-outs 1 wk Mon 7/7/25 Fri 7/11/25 224 210 Backfill to Finish Subgrade 1 day Mon 7/14/25 Mon 7/14/25 209 211 Canopy Foundation 15 days?Fri 5/9/25 Thu 5/29/25 212 Micropiles 1 wk Fri 5/9/25 Thu 5/15/25 205 213 Foundation Pad 3 days Wed 5/21/25 Fri 5/23/25 207 214 Foundation Walls 3 days Mon 5/26/25 Wed 5/28/25 213 215 Backfill 1 day?Thu 5/29/25 Thu 5/29/25 214 216 Set Modular 15 days?Mon 6/2/25 Fri 6/20/25 217 Deliver Modulars 1 day Mon 6/2/25 Mon 6/2/25 16FF 218 Crane Setup & Planning 2 days Tue 6/3/25 Wed 6/4/25 217 219 Set Modular 1 1 day?Thu 6/5/25 Thu 6/5/25 218 220 Set Modular 2 1 day?Fri 6/6/25 Fri 6/6/25 219 221 Make Plumbing Connections 2 days Mon 6/9/25 Tue 6/10/25 160,220 222 Make Water Connections 2 days Fri 6/13/25 Mon 6/16/25 168,221 223 Make Electrical Connections 3 days Tue 6/17/25 Thu 6/19/25 133,222 224 Inspections 1 day?Fri 6/20/25 Fri 6/20/25 223 225 Overlot Grading 15 days Tue 4/8/25 Mon 4/28/25 226 Locates 3 days Tue 4/8/25 Thu 4/10/25 26 227 Strip Topsoil 3 days Fri 4/11/25 Tue 4/15/25 226 228 Survey and set grade stakes 3 days Wed 4/16/25 Fri 4/18/25 227 229 Overlot Grading 1 wk Mon 4/21/25 Fri 4/25/25 228 230 Export Spoils 1 day Mon 4/28/25 Mon 4/28/25 229 231 Demobilize 10 days Mon 6/9/25 Mon 6/23/25 232 Remove Fence 2 days Mon 6/9/25 Wed 6/11/25 233SF 233 Remove Excess Stormwater BMP's 1 day Wed 6/11/25 Thu 6/12/25 234SF 234 Remove Trailer 1 day Thu 6/12/25 Fri 6/13/25 235SF-1 day 235 Clean Up Site 1 wk Mon 6/16/25 Mon 6/23/25 30SF 236 Phase 2 - After July 4rth 83 days?Mon 7/7/25 Thu 10/30/25 237 Re-Mobilize 1 wk Tue 7/8/25 Mon 7/14/25 30 238 Re-Install Fencing 2 days Tue 7/15/25 Wed 7/16/25 237 239 Re-Install Erosion Control Devices 3 days Thu 7/17/25 Mon 7/21/25 238 240 Modular Buildout 10 days Mon 7/7/25 Fri 7/18/25 224 241 Utility connections 5 days Mon 7/7/25 Fri 7/11/25 224 242 Install Masonry 2 wks Mon 7/7/25 Fri 7/18/25 243 Install Lighting 1 wk Mon 7/7/25 Fri 7/11/25 Mar Apr May Jun Jul Aug Sep Oct Qtr 2, 2025 Qtr 3, 2025 Qtr 4, 2025 Task Split Milestone Summary Project Summary Inactive Task Inactive Milestone Inactive Summary Manual Task Duration-only Manual Summary Rollup Manual Summary Start-only Finish-only External Tasks External Milestone Deadline Progress Manual Progress Nottingham Park Improvements Page 7 Project: Preconst Schedule Date: Tue 8/27/24 ID Task Name Duration Start Finish Predecessors 244 Seat Walls 48 days Tue 7/22/25 Fri 9/26/25 245 Demo Asphalt Paths 2 days Tue 7/22/25 Wed 7/23/25 239 246 Subgrade Prep 2 days Thu 7/24/25 Fri 7/25/25 245 247 Excavate Footer/Install Base 3 days Mon 7/28/25 Wed 7/30/25 246 248 Install Foundation base 1 wk Thu 7/31/25 Wed 8/6/25 247 249 Form Walls 1 wk Thu 8/7/25 Wed 8/13/25 248 250 Electrical Rough In 2 days Thu 8/14/25 Fri 8/15/25 249 251 Pour and Strip Walls 1 day Mon 8/18/25 Mon 8/18/25 250 252 Install Support Angles 2 days Tue 8/19/25 Wed 8/20/25 251 253 Install Lath and drainage mat 1 wk Thu 8/21/25 Wed 8/27/25 252 254 Install stone veneer 2 wks Thu 8/28/25 Thu 9/11/25 253 255 Place Precast Cap 3 days Fri 9/12/25 Tue 9/16/25 254 256 Lighting and Power 1 wk Wed 9/17/25 Tue 9/23/25 255 257 Set Light Poles 3 days Wed 9/24/25 Fri 9/26/25 256 258 Paths 7 days Wed 9/17/25 Thu 9/25/25 259 Fine Grade 1 wk Wed 9/17/25 Tue 9/23/25 255 260 Place Asphalt 2 days Wed 9/24/25 Thu 9/25/25 259 261 Canopy Construction 14 days Tue 7/22/25 Fri 8/8/25 262 Set Structure 2 days Tue 7/22/25 Wed 7/23/25 239 263 Install T&G 1 wk Thu 7/24/25 Wed 7/30/25 262 264 Install Underlayment 1 day Thu 7/31/25 Thu 7/31/25 263 265 Install roofing 3 days Fri 8/1/25 Tue 8/5/25 264 266 Install Gutters & Trim 1 day Wed 8/6/25 Wed 8/6/25 265 267 Install Snow Guards 1 day Thu 8/7/25 Thu 8/7/25 266 268 Install Heat Trace 1 day Fri 8/8/25 Fri 8/8/25 267 269 Hardscapes 31 days Tue 7/22/25 Wed 9/3/25 270 South Parking Lot 31 days Tue 7/22/25 Wed 9/3/25 271 Demo Asphalt, Timbers and Trees 1 wk Tue 7/22/25 Mon 7/28/25 239 272 Scarify subgrade 1 day Tue 7/29/25 Tue 7/29/25 271 273 Place and compact Fill 5 days Wed 7/30/25 Tue 8/5/25 272 274 Final Subgrade Prep 2 days Wed 8/6/25 Thu 8/7/25 273 275 Place Curb & Gutter 1 wk Fri 8/8/25 Thu 8/14/25 274 276 Asphalt Prep 1 wk Fri 8/15/25 Thu 8/21/25 275 277 Place Asphalt 3 days Fri 8/22/25 Tue 8/26/25 276 278 Place Rain Garden Media 3 days Wed 8/27/25 Fri 8/29/25 277 Mar Apr May Jun Jul Aug Sep Oct Qtr 2, 2025 Qtr 3, 2025 Qtr 4, 2025 Task Split Milestone Summary Project Summary Inactive Task Inactive Milestone Inactive Summary Manual Task Duration-only Manual Summary Rollup Manual Summary Start-only Finish-only External Tasks External Milestone Deadline Progress Manual Progress Nottingham Park Improvements Page 8 Project: Preconst Schedule Date: Tue 8/27/24 ID Task Name Duration Start Finish Predecessors 279 Striping 1 day Tue 9/2/25 Tue 9/2/25 278 280 Signage 1 day Wed 9/3/25 Wed 9/3/25 279 281 North Parking Lot 17 days Tue 7/22/25 Wed 8/13/25 282 Mill Asphalt 3 days Tue 7/22/25 Thu 7/24/25 239 283 Install leveling bed 1 day Fri 7/25/25 Fri 7/25/25 24,114,282 284 Patch Sewer Line area 1 day Mon 7/28/25 Mon 7/28/25 283 285 Extend Asphalt Limit 2 wks Tue 7/29/25 Mon 8/11/25 283,284 286 Asphalt Overlay 1 day Tue 8/12/25 Tue 8/12/25 285 287 Signs and Striping 1 day Wed 8/13/25 Wed 8/13/25 286 288 Paver Areas 27 days Tue 7/22/25 Wed 8/27/25 289 Survey and Layout 1 day Tue 7/22/25 Tue 7/22/25 239 290 Install Subdrainage (See Utilities)1 wk Wed 7/30/25 Tue 8/5/25 289,193 291 Install class 6 base 2 days Wed 8/6/25 Thu 8/7/25 290 292 Install Edge Restraint 3 days Fri 8/8/25 Tue 8/12/25 291 293 Place Asphalt Base 1 day Wed 8/13/25 Wed 8/13/25 292 294 Perforate Asphalt 1 day Thu 8/14/25 Thu 8/14/25 293 295 Install Filter Fabric 1 day Fri 8/15/25 Fri 8/15/25 294 296 install Fine Grade Sand Bedding 3 days Mon 8/18/25 Wed 8/20/25 295 297 Install Border 1 wk Thu 8/21/25 Wed 8/27/25 296 298 Infill Paving 2 wks Fri 8/8/25 Thu 8/21/25 291 299 Irrigation 56 days Wed 8/6/25 Thu 10/23/25 300 Install Sleeves 1 wk Wed 8/6/25 Tue 8/12/25 273 301 Make Irrigation Tap 1 day Wed 8/13/25 Wed 8/13/25 224,300 302 Run Mainline irrigation Runs 2 wks Thu 8/14/25 Wed 8/27/25 301 303 Install irrigation at North Parking 2 wks Thu 8/28/25 Thu 9/11/25 302 304 Install Irrigation by Modulars 2 wks Fri 9/12/25 Thu 9/25/25 303 305 Install Irrigation at South Parking and Rain Garden 2 wks Fri 9/26/25 Thu 10/9/25 304,275 306 Install Irrigation at Skate Park 2 wks Fri 10/10/25 Thu 10/23/25 305 307 Landscaping 4 days?Mon 9/29/25 Thu 10/2/25 308 Plantings at North Parking Lot 1 day?Mon 9/29/25 Mon 9/29/25 257 309 Plantings by Modular 1 day?Tue 9/30/25 Tue 9/30/25 308 310 Plantings along Seatwall & Entry 1 day?Wed 10/1/25 Wed 10/1/25 309 311 Plantings at Rain Garden 1 day?Thu 10/2/25 Thu 10/2/25 310,278 312 Anticipated Weather Delays 5 days Fri 10/24/25 Thu 10/30/25 244,258,261,299,307 Mar Apr May Jun Jul Aug Sep Oct Qtr 2, 2025 Qtr 3, 2025 Qtr 4, 2025 Task Split Milestone Summary Project Summary Inactive Task Inactive Milestone Inactive Summary Manual Task Duration-only Manual Summary Rollup Manual Summary Start-only Finish-only External Tasks External Milestone Deadline Progress Manual Progress Nottingham Park Improvements Page 9 Project: Preconst Schedule Date: Tue 8/27/24 Town of Avon_East Nottingham Park Improvem ents-Construction Agreement Final Audit Report 2024-12-02 Created:2024-11-25 By:Nicole Mosby (nmosby@avon.org) Status:Signed Transaction ID:CBJCHBCAABAANJ0Q6WHeDta0jXQ1nS29LYn6KDawAzYz "Town of Avon_East Nottingham Park Improvements-Constructi on Agreement" History Document created by Nicole Mosby (nmosby@avon.org) 2024-11-25 - 8:20:11 PM GMT Document emailed to dbaker@bakerbuildersco.com for signature 2024-11-25 - 8:37:03 PM GMT Email viewed by dbaker@bakerbuildersco.com 2024-11-25 - 8:38:18 PM GMT Signer dbaker@bakerbuildersco.com entered name at signing as Dustin Baker 2024-11-26 - 6:45:00 PM GMT Document e-signed by Dustin Baker (dbaker@bakerbuildersco.com) Signature Date: 2024-11-26 - 6:45:02 PM GMT - Time Source: server Document emailed to nina@wwfdlaw.com for signature 2024-11-26 - 6:45:05 PM GMT Email viewed by nina@wwfdlaw.com 2024-11-26 - 6:45:50 PM GMT Signer nina@wwfdlaw.com entered name at signing as Nina P. Williams 2024-11-26 - 6:46:46 PM GMT Document e-signed by Nina P. Williams (nina@wwfdlaw.com) Signature Date: 2024-11-26 - 6:46:48 PM GMT - Time Source: server Document emailed to aphillips@avon.org for signature 2024-11-26 - 6:46:51 PM GMT Email viewed by aphillips@avon.org 2024-12-02 - 4:18:30 PM GMT Signer aphillips@avon.org entered name at signing as Amy Cramer Phillips 2024-12-02 - 4:19:20 PM GMT Document e-signed by Amy Cramer Phillips (aphillips@avon.org) Signature Date: 2024-12-02 - 4:19:22 PM GMT - Time Source: server Agreement completed. 2024-12-02 - 4:19:22 PM GMT 02/14/2025 Flood and Peterson P.O. Box 578 Greeley CO 80632 Kylie Carey, CISR, CIC (970) 266-7148 (970) 506-6845 KCarey@floodpeterson.com Baker Builders, LLC 5660 Iris Parkway Frederick CO 80504-6493 Amerisure Insurance Company 19488 Amerisure Mutual Insurance Company 23396 GL,CAU,WC,XSx4/1/25 A Y CPP21254800001 04/01/2024 04/01/2025 1,000,000 1,000,000 15,000 1,000,000 3,000,000 3,000,000 A CA21254790001 04/01/2024 04/01/2025 1,000,000 Uninsured motorist combined single limit 1,000,000 B 0 CU21254810002 04/01/2024 04/01/2025 5,000,000 5,000,000 A N WC40000170001 04/01/2024 04/01/2025 1,000,000 1,000,000 1,000,000 RE: East Nottingham Park Improvements OWNER, Town of Avon, and its elected officials, officers, employees, and agents are included as Additional Insured as required by written contract for liability caused by the named insured, subject to policy terms, exclusions, and conditions. This Certificate is issued as a matter of information only, confers no rights upon the certificate holder, and does not alter the insurance coverage afforded by the policies described herein. Town of Avon P.O. Box 975 100 Mikaela Way Avon CO 81620 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. INSURER(S) AFFORDING COVERAGE INSURER F : INSURER E : INSURER D : INSURER C : INSURER B : INSURER A : NAIC # NAME:CONTACT (A/C, No):FAX E-MAILADDRESS: PRODUCER (A/C, No, Ext):PHONE INSURED REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. OTHER: (Per accident) (Ea accident) $ $ N / A SUBR WVD ADDL INSD THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $ $ $PROPERTY DAMAGE BODILY INJURY (Per accident) BODILY INJURY (Per person) COMBINED SINGLE LIMIT AUTOS ONLY AUTOSAUTOS ONLY NON-OWNED SCHEDULEDOWNED ANY AUTO AUTOMOBILE LIABILITY Y / N WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OFFICER/MEMBER EXCLUDED? (Mandatory in NH) DESCRIPTION OF OPERATIONS below If yes, describe under ANY PROPRIETOR/PARTNER/EXECUTIVE $ $ $ E.L. DISEASE - POLICY LIMIT E.L. DISEASE - EA EMPLOYEE E.L. EACH ACCIDENT EROTH-STATUTEPER LIMITS(MM/DD/YYYY)POLICY EXP(MM/DD/YYYY)POLICY EFFPOLICY NUMBERTYPE OF INSURANCELTRINSR DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) EXCESS LIAB UMBRELLA LIAB $EACH OCCURRENCE $AGGREGATE $ OCCUR CLAIMS-MADE DED RETENTION $ $PRODUCTS - COMP/OP AGG $GENERAL AGGREGATE $PERSONAL & ADV INJURY $MED EXP (Any one person) $EACH OCCURRENCE DAMAGE TO RENTED $PREMISES (Ea occurrence) COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO-JECT LOC CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) CANCELLATION AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. CERTIFICATE HOLDER The ACORD name and logo are registered marks of ACORD HIRED AUTOS ONLY